
    John Canavan and Others, Appellants, v. Christopher Nally, Respondent, Impleaded with The Mayor, Aldermen and Commonalty of the City of New York and Others.
    
      Mechanic’s lien filed by a sub-contractor — counterclaim for the expense of remaning stone placed by the sub-contractor on city land.
    
    In an action to foreclose a mechanic’s lien, filed hy a sub-contractor, a counterclaim, to the effect that the sub-contractor dumped rock near thé contractor’s work on land owned by the city of Hew York, with which the principal contract was made, which stone the engineer insisted that the contractor should, and which he did, remove before the engineer would give him a certificate — there being no proof of the contractor’s obligation to remove this rock from the city’s land — cannot be sustained.
    Appeal by the plaintiffs, John Canavan and others, from a judgment of the Supreme Court in favor, of the defendant, Christopher Nally, entered in the office of the clerk of the county of New York on the 9th day of April, 1897, upon the decision of the court rendered after a trial at the New York Special Term dismissing the complaint and granting the defendant, Christopher Nally, affirmative relief upon certain counterclaims.
    The action was brought to foreclose a lien filed by the plaintiffs against moneys owing by the city of New York to the defendant Nally upon a contract between him and the city for the construction of a retaining wall along Riverside Drive, between Seventy-ninth and Ninety-sixth streets. The claim set out in the complaint is for excavation done pursuant to a contract in writing, dated August 1, 1894, whereby the plaintiffs agreed to furnish the labor and material for excavating and to excavate 728 cubic yards of rock as per measurement of the surveyor employed by the defendant Nally, and to break up in sizes "required for backing at least 400 cubic yards of the material excavated, for which they were to be paid $2,500 ; and further agreed to rent to the defendant Nally “ when not in usé on this work, their steam boiler, hoister and derrick,” for which Nally was to pay “ when retained hy him ” $10 per day, and “pro rata for parts of days when said steam boiler, hoister and derrick are retained by them; ” under which contract the plaintiffs claim they became entitled to receive from Nally, in addition to the $2,500 for excavation, $1,350 for the use of their" steam boiler and two lioisters and derricks. The plaintiffs also claim for extra work outside of the contract $474.50, made up as -follows: For cutting steps in rock, $108; for hauling stone and cement, $67.50; for boring with steam drills rock not to be excavated, $287; and for a new boom for derrick, $12. On account of these claims the plaintiffs allege a payment of $3,000, leaving a balance of $1,324.50.
    The defendant Rally’s answer admits the amount due to the plaintiffs for excavating, $2,500, and the claim for use of derricks to the extent of $779; and with respect to the extra work he admits the charge for cutting steps, $108 ; and for team hire, $67.50; upon account of which he alleges he has paid the plaintiffs $3,012. To offset the balance, he makes a counterclaim of damages for failure of plaintiffs to break up 400 cubic yards of rock as provided by said contract, $71.67; work performed for the plaintiffs at their request, $105.80; 1,545 loads of earth filling furnished by the plaintiffs, for which a previous contract between the plaintiffs and Rally provided that they should pay him 25 cents a load, $340.40 ; damages for failure by the plaintiffs to furnish suitable stone pursuant to such previous contract, $33 ; and damages-by reason of large rocks being willfully dumped by the plaintiffs along the line of defendant Rally’s work in Riverside Park, $1,810.67; making a total of $2,361.54, and leaving a balance claimed -to be due to the defendant Rally of $1,919.04.
    By the judgment the plaintiffs were allowed :
    For excavation......................... $2,500 00
    For use of derricks.................... 779 00
    For cutting steps....................... 108 00
    For team hire......................... 87 50
    - $3,454 50
    And the defendant Rally was allowed:
    For labor and material.................. $105 00
    For earth filling....................... 340 40
    For breaking up and disposing of stones dumped by plaintiffs in Riverside Park.. 936 68
    For damages because plaintiffs did not complete their contract in the required time. 140 00
    And for money paid plaintiffs............ 3,012 00
    $4,520 08
    
      Leaving a balance in favor of the defendant Rally of $1,074.58 ; which is stated in the judgment to be $1,072.58.
    The plaintiffs admit the defendant Rally’s counterclaim for labor and materials of $105 ; and, as stated, admit the payment of $3,000, but they except to the items allowed to Rally for earth filling, for breaking up and disposing of the stone, and for damages, because of delay in completing contract. The plaintiffs further insist that their full claim for derrick hire should have been allowed, as well as their claim for a new boom for derrick, and for extra work in drilling rock.
    It appears that more than a year previous to entering into the contract for excavating, and on July 24, 1893, the plaintiffs, by a written contract, in consideration of the sum of one dollar, had agreed to furnish to the defendant Rally all the stone that he might require for foundation masonry at such times and places, and as the same were needed, along the line of the defendant Rally’s work between Seventy-ninth and Rinty-sixth street; such stone to be large and well shaped, as nearly rectangular as possible, and generally not less than six inches thick. In addition the contract provided: “ For all filling of mould or clean earth which may be required by the party of the first part (Rally), the party of the second part (the plaintiffs) agrees to pay to the party of the first part the sum of twenty-five cents per load.”
    
      L. Laflin Kellogg, for the appellants.
    
      Mortimer M. Menken, for the respondent Nally.
   O’Brien, J.:

With respect to the items in dispute, we will first consider in their order those advanced by the plaintiffs. We have, first, the item for extra work in drilling holes in rock at a place where it is conceded drilling was unnecessary, but concerning which there is a conflict as as to whether the work was done by reason of the mistake of the plaintiffs or of the defendant Rally; second, the difference between the amount claimed and that allowed for use of derricks, as to which the evidence was also conflicting; and, third, the charge of twelve dollars for a new boom, which the plaintiffs say Rally never paid, but which he testified he did pay. As these presented clean-cut questions of fact, upon conflicting evidence which was in no sense preponderating, we see no reason to interfere with the decision reached by the-judge below. For a similar reason we must sustain the conclusion reached as to one of the items allowed of the defendant’s counterclaim. With respect to the earth filling, there was no question but that the number of loads' allowed for, at twenty-five cents a load, was delivered, the conflict, however, arising as to whether there was a modification of the original agreement under which the plaintiffs were to pay such twenty-five cents, so as to permit them to have a free dump, provided they would furnish the labor for spreading the dirt. Such a modification of the contract is denied by Nally, and the court accepted his version.

There remain for consideration, however, two items of the defendant’s counterclaim which, we think, were erroneously allowed. The first amounted to $938.68, for breaking up and disposing of large foundation stones. The defendant testified that he gave the plaintiff the privilege of putting in 400 yards of rock for foundation masonry, and that when about that amount had been delivered he notified one of the plaintiffs not to deliver any more stone; but that, though the latter promised to comply with the request, he thereafter continued until he had dumped over 2,000 yards of stone. This, the defendant states, he requested the plaintiffs to remove, which they promised, but afterwards refused to do; and that eventually the defendant had to break the stone up and haul it with teams, putting some of it behind the wall in place of qartli filling, and in other places as directed by the engineers, at a cost to him of $849.68. To this the judge below added $59, presumably for interest, bringing the amount up to $938.68. According to the testimony of the city engineer, he directed Nally to clear up the rock; and it would, therefore, appear that the plaintiffs have been charged with the expense placed upon Nally by the city engineer of clearing the ground of stone. Upon the part of the plaintiffs there was a denial of any limitation as to the amount of stone that should be delivered. It also appeared that there were others, or, at least, one other contractor, who dumped stone, as he testified, along the line of the work. For the stone dumped by others the plaintiffs should not be held accountable. Nor do we know of any principle of law upon which the plaintiffs can he required to reimburse the defendant Nally for the cost to which he may have been put by the city engineer in removing from the ground the stone placed there by plaintiffs. This was not shown to be part of Nally’s contract with the city; and the suggestion that, unless he did it, he could not receive the certificate, so as to obtain payment, was not a sufficient justification for doing it and then charging the plaintiffs with the cost thereof, because, if it was no part of his contract, he was entitled to his pay without complying with any such condition.

Apart, however, from this, the land upon which the stone was dumped belonged to the city and not to Nally; and, therefore, the acts of the plaintiffs in placing the stone there, if done without permission, was a trespass upon the city’s property, for which the latter might have had a remedy over against the plaintiffs, but with which, so far as the record discloses, the defendant had no relation other than that he was engaged in doing the work specified in his contract with the city. This gave him no such relation to the property as to entitle him to obtain damages from persons who might trespass upon the land or injure it by dumping stone thereon, and certainly it did not entitle him to recover from the plaintiffs for stone dumped by other persons.

Equally without support is a similar item of $140, representing the wages of the city inspector for thirty-five days at four dollars a day, which was charged against the plaintiffs upon the testimony appearing that it took the defendant thirty-five days to clear away tlie material dumped by the plaintiffs along the line of his work and which the engineer told him it was necessary to remove before he would sign the certificate to obtain his pay from the city. What we have already said about the removing of the rock applies equally to this item. Unless the defendant Nally was under a contract obligation, or had such a relation to the property that he could insist upon recovering damages for what he alleges were the plaintiffs’ wrongful acts, it should not be allowed him. As we have already pointed out that no such relation existed, and that no such obligation was imposed upon the defendant, this, like the previous item, must fall.

The judgment should, therefore, be modified by deducting from the amount allowed to the defendant Nally by the court below these two items, amounting to $1,078.68; the result of which will be a judgment in plaintiffs’ favor of $6.10 ; neither party to have costs here or in the court below.

Van Brunt, P. J., Williams, Patterson and Ingraham, JJ., concurred.

Judgment modified as directed in opinion, without costs to either party.  