
    George K. Chase, plaintiff and appellant, vs. Roswell D. Hatch and others, ex’rs, &c. of Robert Hogan, deceased, defendants and respondents.
    1. When a vendee of land has either failed to complete the erection of a house thereon, by a day designated in the contract of sale thereof to him, or suspended work thereon for over ten days, contrary to an agreement by him in such contract, a sale by the vendor to a third person of all the right, title and interest of the vendee in such contract and in such land, pursuant to an authority reserved to him to that effect in case of such failure or suspension, is valid and binding on such vendee; and passes all such right and interest to the purchaser.
    2. So Held, where the contract provided for the conveyance of such land by the vendor to the vendee upon the completion of such house, and also for the execution by the latter of a mortgage upon the premises for the purchase money, and any moneys advanced, by the former to the latter, to aid him in building such house, pursuant to an agreement in the contract, and where, by the terms of such contract, the proceeds of such sale by the vendor, after deducting expenses, were to be applied to his reimbursement for any moneys which he might have so advanced, pursuant to the agreement.
    
      3. Upon such a contract, the vendee who had commenced such building, but sus - pended his work thereon for over ten days, and for nearly three months before the time fixed therein for its completion, could not sue at common law for damages for non-delivery of the deed to him, or cm a quantum meruit for the value of the materials furnished or work done towards such building, or bring any action for the recovery .of possession of the premises, His remedy, if any where, was in equity.
    4. In order to obtain any relief in equity, a vendee so situated was bound to shew a sufficient excuse for not completing such building in time. His mere loss of materials, or work, did not constitute a sufficient equity for that purpose.
    5. A provision in such contract for the right of the vendor to insist upon the immediate payment of any advances made by Mm under it, and the authorization of Mm therein to sell the vendee’s interest in case of a suspension of work upon the house for ten days, or his failure to complete it within the time fixed, did not affect the right of such vendor to resist an action for specific performance, by reason of the failure of the vendee to perform the condition precedent of completing the house in question by the day fixed in the contract. Those causes did not affect the rights of either party arising out of such nonperformance,
    6. The non-essentiality of time to the right of enforcing a contract for the sale of land, does not involve such an entire disregard of the specification of a time therein for its performance as not to require some excuse for its neglect or attempt to palliate its evils. A party who has failed, at the day fixed, to demand performance or to perform what was necessary to entitle him to it, if he cannot excuse his neglect, or show the acquiescence of the other party in it, must show, at least, due diligence in repairing its consequences, and enforcing his rights.
    . (Before Moheul, Garvin and Jones, JJ.)
    Heard February 16, 1866;
    decided March —, 1866.
    m
    This action was brought upon a contract made between Chase, the plaintiff, and one Robert Hogan, dated September 18, 1856, by which Hogan agreed to sell, and the. plaintiff to purchase, a certain lot of land for $5000, and the plaintiff agreed to erect on said lot a house, which should be fully completed before May 1, 1857. Hogan agreed to loan tó Chase, to aid him in the erection of said house, $2500, in 12 installments, and upon the completion of the said house, to deliver to the plaintiff a warranty deed of the lot free from all taxes and assessments to the date of the agreement. The purchase money of the lot, and the sum to be advanced to aid in the erection of the building, was to be paid by the plaintiff to Hogan by his bond, secured by a mortgage on the premises,' bearing even date with the agreement, and to be executed and delivered simultaneously with the deed. The bond and mortgage were to bear interest on the amount of the purchase money from the date of the contract, and on the advances, from the ■ dates on which they should be made. The mortgage was to contain an insurance clause, by which the premises were to be kept insured in a sum of not less than $3000. After these provisions, the contract provided that: if Chase failed “ to complete said intended house, or if the diligent prosecution of the work thereon shall, at any time after the date of these presents, be suspended for ten days,” Hogan should “ have the right to insist on the immediate repayment of all the advances he might have made, together with the interest thereon.” He was also thereby “ authorized in such case, to sell at public or private sale all the estate, right, title and interest of said Chase in and to said premises, and apply the proceeds of such sale to the payment and satisfaction of the expenses of such sale and of all claims and demands due thereon, or after to become due,” which he might have against Chase, for and on account of “ such premises.” If any surplus remained, it was to be paid to Chase. Hogan, however, was to give Chase “ ten days notice in writing of his intention to make such sale.”
    The complaint sets forth this contract in detail, and alleges that, under it, the plaintiff went into possession of the premises, and during the fall of 1856 was proceeding to erect thereon the house called for by the contract, and had progressed to the fourth tier of beams, when the winter weather rendered it unfit to proceed further until the ensuing spring ; that he had expended in said erection $3000 ; that in April, 1857, Hogan, pretending that the ten days suspension of diligent prosecution had elapsed, claimed to exercise acts of ownership over the property, and expel the plaintiff from possession of the same, without in any lawful manner proceeding to change the relation of the parties in their existing rights ; that the plaintiff has never refused, or in any manner neglected, to proceed with the ,vork, except in consequence of such expulsion from the premises by the defendant; that no proceedings at law, or equity, have been taken by either party to foreclose the plaintiff’s interest, or divest him of his right in said property; but that the buildings have ever since remained in that unfinished and unprotected state by reason of the defendant’s conduct afore•said ; that the plaintiff was ready and willing to proceed, and, by his complaint, offered to comply in all things with the requirements of the said contract on his part, except that which he claimed to have been waived by the defendant.
    The relief demanded in the complaint was that the omission of the defendant to call 'on the plaintiff to execute an assignment of his interest in said contract might be declared a waiver of his right to do so in pursuance of any sale in consequence of such suspension of the work; and that said contract might be declared in full force and effect, and that the plaintiff might be permitted to proceed with the execution of the same, or that the plaintiff’s interest in said contract might be sold under the direction of the court, and the proceeds thereof appropriated as should seem just; and, also, specific or general relief.
    The answer denied that the plaintiff expended towards the erection of the house the sum mentioned in' the complaint. It alleged that the plaintiff continued to erect the building until about February 23, 1857, when he wholly ceased to work thereon, and never afterwards proceeded therewith, but wholly neglected and refused to proceed and complete the same, leaving the same partially unfinished. It then alleged that up to said February 23, 1857, the defendant had advanced to the plaintiff under the contract, $850. It then alleges that about April 15, 1857, the plaintiff having suspended work for more than ten days, he, the defendant, gave the plaintiff written notice that he would sell at public auction in the city of New York all the right, title and interest of the plaintiff in said contract, if said plaintiff did not before the expiration of ten days thereafter repay him, the defendant, all sums paid by him to said plaintiff upon said contract, together with interest thereon, and all other charges thereon. It further alleged that the plaintiff, still neglecting to go on with said building, he, the defendant, after having given public notice thereof in the newspapers published in the city of New York, sold at public auction at the Merchants’ Exchange in said city, on the 12th day of May, 1857, all the right, title and interest of the plaintiff in said premises, and the building partially erected thereon, and then and there became the purchaser thereof for §10. It then claims that, after the sale, all the right of the plaintiff was by reason of the matters aforesaid wholly extinguished, and that he, the defendant, was then the lawful owner thereof. It denies all the allegations of the complaint inconsistent with the answer. It sets up the making of a contract after said sale of the plaintiff’s interest, he, the defendant, being in possession of said premises, and said contract still remaining unperformed by the plaintiff, and before the commencement of this action, to wit, on or about June 1, 1858, between the defendant and one Mr. Mee, in reference to said premises, similar in its provisions to the one made with the plaintiff, and Mee proceeding under such contract to erect a dwelling house on said lot of the value of from §12,000 to §15,000, and that he had nearly completed the same. It then prays that upon any recovery by the plaintiff he be only entitled to any amount expended before such sale of his interest in such contract, after deducting therefrom any and all advances by the defendant, with interest thereon, and all other" claims against him, the plaintiff, by the defendant under such contract; and that said Mee remain in possession under the contract between him and the defendant. The cause was tried at special term, before a single judge without a jury.
    On the conclusion of the testimony on both sides, the defendant moved for a dismissal of the complaint on the grounds,
    1. No performance is shown by the plaintiff.
    2. No excuse for non-performance is shown.
    The judge reserved the decision of the motion.
    The counsel for the defendant then made several requests at the trial to the judge to find several facts, and state several principles of law, which he refused, and to such refusal the counsel for the plaintiff excepted.
    
      Thereupon the court found afterwards by its decision, as matters of fact,
    1st. That the agreement above set forth was entered into between the plaintiff and Eobert Hogan about the 18th of September, 1856.
    2d. That thereupon the plaintiff entered into possession of the premises and commenced the erection of a dwelling house in conformity with said agreement, and continued his work until the latter part of February, 1857, when he suspended the work and did not resume the same.
    3d. That on the 17th of April, 1857, Hogan served on Chase a notice dated April 15, 1857, that after ten days from the date thereof he should sell at public auction all the estate, right, title and interest of him, the said Chase, in the contract, unless he the said Chase should, before the expiration of said ten days, repay and reimburse him, the said Hogan, for all the money he had paid out on the contract, together with interest and other charges incurred.
    4th. That after service of notice on Chase, said Hogan caused a notice that he would sell at the Merchants’ Exchange, at 12 o’clock on Tuesday, May 12,1857, all the estate, &c. of said Chase in said premises to be published in the Evening Post on the 5th, 6th, 7th, 8th, 9th, 10th and 11th days of May, 1857, and in the Morning Courier and Hew York Enquirer on the 6th to the 12th days of May, 1857, both inclusive.
    5th. That no notice of the time and place of. sale was given to the plaintiff, and he had no knowledge thereof.
    6th. That on the 12th of May, 1857, at the time and place specified in said notice mentioned in above 4th finding, all of the estate, &c. of said Chase in said premises was put up at auction for sale by E. H. Ludlow, auctioneer, and was struck down to Hogan for $ 10, he being the highest bidder, and that being the highest sum bidden for the same.
    7th. That the plaintiff violated his contract with the defendant by the total suspension of all work on said house and by the non-completion of said house on the 1st of May, 1857.
    8th. That on the 1st of June, 1858, prior to the commencement of this action, Hogan made with one John B. Mee a contract in reference to said premises similar in its provisions with that made by him with the plaintiff, under which agreement said Mee entered into possession of said premises and proceeded to fulfill the contract on his part, and since the commencement of the action, had received a deed of said premises.
    9 th. That the value of said premises with the building thereon, in the condition it was when the sale was made to said Mee, was $7900.
    10th. That the price agreed to be paid by the plaintiff under his contract with Hogan, with interest thereon to June 1, 1858, is $5595.97; and the amount of advances made to the plaintiff by Hogan, with interest thereon from the time they were made, up to said June 1, 1858, is $936.26, the two sums together making $6532.23, and leaving a balance when deducted from the value of the premises at the time of the sale to said Mee of $1367.77.
    The court found, as matters of law, upon the above found facts,
    1. That the plaintiff is not entitled to judgment for specific performance.
    2. By the public auction sale, Hogan acquired no right and the plaintiff was not divested of his right, title or interest or estate in said premises.
    3. By the private sale to said Mee the plaintiff was not divested of his estate, &c. in said premises.
    4. Substantially that the plaintiff is entitled to be credited with the sum of $7900, and is chargeable with the sum of $6532.23, and that he is entitled to recover of the defendants the sum of $1367.77, with interest thereon from December 28, 1864, the date of the report of the referée to whom it was referred to take and state the accounts, &c. amounting in the aggregate to $1456.33 ; for which amount, with costs to be adjusted, the court directed judgment in favor of the plaintiff, against the defendants.
    Judgment was entered accordingly ; from which judgment this appeal is taken.
    
      It was not found expressly by the court in its decision that there was any excuse or justification for the non-performance. The plaintiff, however, gave evidence of two matters on which he relied as affording an answer and justification, to wit, the state of the weather, and his illness.
    
      E. P. Howies, for the appellants, defendants.
    
      G. A. Eavison, for the respondent, plaintiff.
   By the Court,

Jones, J.

It will be perceived that one of the findings by the court below is, That about the 18th September, 1856, the plaintiff entered upon the possession of the premises mentioned in the complaint, and commenced the erection of a dwelling house thereon, in conformity with said agreement, and continued the work thereon, until about the latter part of February, 1857, when he suspended said work and did not resume the same.” And another finding is, that the plaintiff violated his contract with the defendant’s testator by the total suspension of all work, and by the non-completion of said house on the 1st of May, 1857, the'day limited by the contract for its completion.

The question then arises, what is the effect of this breach of contract by the plaintiff ?

At common law, under the cases of Champlin v. Rowley, (18 Wend. 193,) Harmony v. Bingham, (12 N. Y. Rep. 99,) Smith v. Brady, (17 id. 173,) Tompkins v. Dudley, (25 id. 272,) and Catlin v. Tobias, (26 id. 217,) the plaintiff was guilty of a breach of his contract, and having failed to fully perform the condition precedent to his right to receive the deed, by omitting to erect the building by the day limited, he could neither bring an action for damages based on the defendants’ refusal to deliver the deed, nor an action on the quantum meruit, for the work actually performed, and materials actually .furnished; but the defendant, under the authority of Jackson v. Moncrief, (5 Wend. 26;) Wright v. Moore, (21 id. 230,) could at law bring an action of ejectment, to recover possession of the property.

The defendants having peaceably obtained possession, there is no necessity for them to bring the possessory action of ejectment.

The remedy of the plaintiff, if he has any, is in equity. (Wright v. Moore, 21 Wend. 230.) The plaintiff has in fact brought an action in equity, to obtain possession and protect such rights and interests as he claims to have. He claims that in equity there is a principle, to the effect that time is not an essential part of a contract; that in this case time would not in equity be regarded as of the essence.of the contract, and consequently, although he has not performed by the time limited, he is yet entitled to relief in equity.

It is true it is stated in many English and American cases that in a contract for the sale and purchase of land, the time limited for the completion of the sale and purchase is not in general regarded in equity as an essential part of the contract.

I do not, however, understand this doctrine to extend so far as to enable a party to obtain relief against non-performance by the day, in cases where he shows neither any good reason for such non-performance, nor any peculiar equity.

Chancellor Kent, in Benedict v. Lynch, (1 John. Ch. 370, cited from pages 375, 376, 379,) observes: “It may then be laid down as an acknowledged rule in courts of equity, that when the party who applies for a specific performance has omitted to execute his part of the contract, by the time appointed, without being able to assign any sufficient justification or excuse for his delay, and when there is nothing in the acts or conduct of the other party that amounts to an acquiesence in that delay, the court will not compel a specific performance. The notion that a party may be utterly regardless of his stipulated payments, and that a Court of Chancery will almost at any time relieve him from the penalty of his gross negligence, is very injurious to good morals, to a lively sense of obligation, to the sanctity of contracts, and to the character of the court.. It would be against all my impressions of equity to help those who show no equitable title to relief.”

He 'then, after remarking that it was formerly supposed that the time fixed on for the completion of the contract was quite immaterial, proceeds to review the cases, and after such review observes: From the review which I have taken of the

cases, the general principle appears to be perfectly established, that time is a circumstance of decisive importance in these contracts, but it may be waived by the conduct of the party; that it is incumbent on the plaintiff calling for a specific performance, to show that he has used due diligence, or if not, that his negligence arose from some just cause, or has been acquiesced in.”

There is no case, (not even those where it is asserted that time is not of the essence of the contract,) which does not require the plaintiff to show at least thus much, to entitle himself to relief.

In the case at bar, the plaintiff does not bring himself within these principles.

The court below has not found as a fact, nor does the testimony satisfactorily show, that there was any excuse for the delay ; nor does there appear to be any special equity.

It is true, the defendant swears he was sick, from 5th or 6th April, till after May 1st. This, however, could not excuse the suspension of the work, .from the latter part of February to the 5th of April, a period of six or seven weeks. Non constat but that if he had prosecuted the work diligently during that period, he would have finished the work before he was taken sick. Nor does it appear how sick he was ; he may not have been so sick as to prevent him from finishing the house through the agency of others; He does not swear he was, and he does not testify that this sickness prevented him from completing. All this is to be inferred from the. bare fact that he was sick. I think the fact does not justify the inference,

It is also true, that the defendant testifies that he proceeded as fast as the weather would permit, and with as many men as could work then to advantage, considering the weather up to the time he was taken sick. At fol. Ill he testifies that he was going on with the work all the time, except when the weather prevented, from the 29th of March to April 6. As I understand this testimony, he says, that he went on with the work up to the 29th of March, .and that it was only from the 29 th of March to April 6 th, that the weather prevented its prosecution.

The court below found that he absolutely ceased work in the latter part of February,- a month prior to March 29. This finding is in direct conflict with the plaintiff’s testimony at fol. Ill and 130. With the discredit cast by this finding on the plaintiff’s testimony on this material point, the court, on appeal, should attach but slight importance to the evidence of sickness.

The testimony at folio 111, seems to me, to dispose of the excuse arising from the weather. That testimony shows that the only delay caused by the weather was eight days, from March 29 to April 6. Thus there is over a month of total suspension left unaccounted for. This unexcused delay of one month; leads to the conclusion that the assigned cause, of weather and sickness, did not prevent the performance, but that some motive which was not disclosed led to the nonperformance, and that the weather and sickness were first thought of as excuses when this action was commenced.

Upon the evidence, if the case were tried before me, I should feel very unwilling to find that non-performance by the day was prevented either by the weather, or sickness, or both combined. Feeling thus, I cannot on this appeal find such to be the fact, for the purpose of sustaining the judgment below, when the judge below has not chosen to base his decision on the assximption of the existence of such facts.

It is also true, that if the plaintiff is not relieved, he will suffer a loss of time and materials. That bare fact, however, constitutes no special equity ; it is common to all cases. As the case at present stands, this loss appears to be the result of the plaintiff’s own culpable negligence ;' and he cannot call on equity to relieve him from it. Besides, it does not appear that the value of 'the time and materials is more than sufficient to reimburse the defendant for his advances, interest thereon, and interest on the purchase money. .

For these reasons, it would be improper for the court to compel a specific performance. The same reasons would also debar the plaintiff from recovering damages in a court of equity. If by reason of his default the court declines to decree specific performance, it will also decline to award damages.

Thus, neither under the principles of the common law, nor those of equity, is the plaintiff, as the case now stands, entitled to any damages ; unless the clauses in the contract relative to the sale of the plaintiff’s interest have the effect of depriving the defendant of this right, which he would otherwise acquire, by reason of non-performance by the day.

I think these clauses have not such an effect. The tenor of them seems to be to enable the defendant to press forward the work in case of delay during the running of the contract; so, also, in case of an abandonment, or refusal to proceed during the running of the contract, to provide a means by which the defendant, without waiting for the contract to expire by limitation, may obtain repayment of his advances, with interest, and terminate the contract.

■ These clauses give to the defendant rights which he otherwise would not possess. They were inserted for the benefit and protection of Hogan, not of Chase. They give Hogan the right, if he saw fit to exercise it, to terminate the contract in a certain manner prior to its expiration. There is nothing, however, compelling him to exercise that right. It was entirely optional with him. He might wait until the time limited for performance expired, and then, in case of non-performance, put the contract at an end and resume possession of the property, saying, I do not desire to exercise the right given me by these clauses for my benefit and protection. A review of all of the provisions of the contract shows this to be the proper construction of these clauses. The defendant was to sell the land and make advances, to give a deed on the completion of the house, and to take back a mortgage for the purchase money, the advances and interest thereon. . The contract provides that the house should be completed prior to the first of May, and that the deed and mortgage should be delivered on the completion of the house.

It is evident that the defendant had a great interest in having the house completed as soon as possible, for it was on the mortgage that he relied for his security for the purchase money of the land and for his advances ; and also that he might devise some means whereby he might readily avoid making further advances, and recover back that already made, in case the house did not progress satisfactorily.

Under the circumstances, the defendant may well have said to-Chase,. “ I wish some provisions inserted whereby I may, if you are dilatory, spur you up so as to get this house completed as much before the 1st of May as possible, and so that if you at any time before May 1st abandon or refuse to go on with the contract, I may readily get back my advances, and get rid of you ;” and Chase may well have replied to this, Y ery well, I see no harm in this ; I have contracted to finish the house before the 1st of May, and expect to do so, therefore, said provisions cannot, as I see, hurt me.”

Therefore, the provisions were agreed on, and inserted. But to proceed a little further. Chase contracted to finish the building by May 1st. It is fair to presume that he intended and anticipated to be certainly able to comply with the contract. There is nothing in the contract which suggests that Chase had in his mind the possibility of .being prevented from complying, by any casualty ; therefore, the provisions in question could not have been inserted for his benefit or protection, in this respect.

Again, the provisions could not have been inserted with the view of benefiting or protecting the plaintiff in the event of his non-performance by the day, either negligently or willfully. It cannot be conceived that the defendant would consent to such a premium on negligence or willfulness;. besides, it is contrary ' to the spirit of the provisions.

Thus, the whole context of the contract, as well as the peculiar wording of the provisions, lead irresistibly to the conclusion, that the sole effect of the clauses is to invest the defendant, for his sole benefit and protection, with certain rights, which he might, or might not, at his option, exercise during the running of the contract; that this is their only object, and that it was so understood and intended by both parties when the contract was made.

It follows, as a necessary consequence, that these clauses have (if they have not been effectively exercised before the 1st of May) no effect whatever on the legal rights and remedies of either party arising from non-performance by the day.

The following questions, viz. 1st. Whether a court of equity will require stronger grounds to induce, its interference to relieve from the consequences of non-performance by the day in cases where it considers time to be of. the essence of the contract than in cases where it considers time not to be of the essence; 2d. As to whether in the contract in question, time is of the essence or not •; 3d. As to whether a delay of one year in bringing suit would not be regarded as such an acquiescence as that the court would grant no relief even in cases where time was not of the essence; 4th. As to whether under a proper construction of all the decisions, time is not always of the essence; 5th. As to whether a court of equity can, in any case, decree damages except in lieu of a specific performance which it decrees the plaintiff entitled to, but which cannot be enforced in consequence of the defendant’s inability to perform ; 6th. And as to whether when defendant’s inability to perform arises before the commencement of the action, the court can, in any case, decree damages in lieu of a specific performance, which it seems the plaintiff would have been entitled to, had it not been for such inability of the defendant, have not been considered or determined.

It is unnecessary to consider the 1st, 2d and 4th queries, since the conclusion has been arrived at that -even under the equity principles applicable to contracts, when time is not of the essence, the judgment cannot be sustained on the facts found, nor on those facts with other uncontroverted facts in the case. It is also unnecessary to determine the 5th and 6 th queries, since the case as presented is not one in which damages can he awarded. On a new trial, a case may possibly be made which will raise these questions; it will be more proper to determine them then than now.

The third query is more properly a matter of evidence. Answering it in the negative, would not entitle the plaintiff to hold his judgment, since it is reversed on considerations entirely disconnected with this one. An affirmative answer, on the other hand, would not only call for a reversal of this judgment but a rendition of judgment absolute for the defendant.

It is a matter which undoubtedly would have a great bearing on the question, whether any relief should be granted. Its force, however, may be strengthened or weakened by other matters ; thus, if at the time of the suspension of the work, the market was such that the plaintiff anticipated a loss on the contract, that would account for the suspension; and if at the time of commencing the suit, the market had so improved as to render a profit certain to arise from completion, that would account for the suit. Under these circumstances, the year's delay would probably be an absolute bar, under the cases of Rogers v. Saunders, (16 Maine Rep. 92, 99,100,) and Alley v. Deschamps, (13 Vesey, 228.) On the other hand, its effect may, by circumstances to be proved, be either greatly weakened or wholly destroyed. I do not, therefore, think it advisable to determine its effect, on this appeal.

A few words respecting the decision made by a former general term of this court, in this case.

That decision was rendered on an appeal taken from a judgment entered on a decision made upon a former trial. The judge, before whom that former trial was had, held that the parties by the special provisions before alluded to had prescribed the mode in which the plaintiff's interest was to be foreclosed in case of default, and that the defendant had not properly pursued that mode, in that he had become the purchaser at the sale made under those provisions. He therefore held that such purchaser could not be allowed to foreclose the plaintiff from a right to an account, and consequently directed an account. His findings of facts upon which he rendered this decision were substantially the same as those before us on this appeal. There does not, however, appear to have been any evidence tending-to show any reason for non-performance, and there was a finding that Chase had furnished materials and performed labor to the amount of $3040.88. These constituted the only differences between the case as then and as now presented to the appellate court.

The appeal taken from the judgment entered upon such former special term decision was heard before two judges only. One of the judges held that as the plaintiff had shown no excuse for the non-performance, he could not recover damages at law, nor could he obtain either a specific performance or damages in equity. He also held the special provisions and the acts done thereunder could have no bearing whatever in the determination of the rights of the parties. He also held that while the plaintiff was not entitled to recover any thing, the defendant was entitled to recover damages against the plaintiff for non-performance. He also held that if the action could be maintained, in any shape, the defendant should be allowed, in diminution of the plaintiff’s claim, for the damage to the building by the weather. He therefore decided that the judgment should be reversed and a new trial had.

The other judge, without considering the case in the aspects in which his associate had considered it, proceeded to discuss the point whether the defendant could rightfully purchase at the sale made by him, and then, without coming to any conclusion on this point, states that the principle on which the account was taken below, was erroneous, for the reason that no allowance was made for the damages sustained by the building by exposure to the elements, intermediate the time when the plaintiff abandoned the work and the subsequent sale of the premises. He then lays down what he regards as the true principle, and decides (but his opinion furnishes no clue to the ground on which he bases the decision,) that if on an account taken on such principle, a balance should be in favor of the plaintiff, Hogan should pay that balance, but if the balance should be in favor of Hogan, he should have judgment for it. On the ground, then, that the principle of the account as taken in the court below was erroneous, that the plaintiff was entitled to an account to be taken on certain other principles, and that the party in whose favor the balance should be found to be, on such new accounting, was entitled to judgment against the other, he concurred in reversing the judgment below and granting a new trial.

It is apparent that on that appeal nothing was decided except that, assuming this action could be maintained in any shape, the defendant should be allowed for the damages to the building by the weather. It may then be regarded as the law of this case that the defendant is entitled to such allowance if the plaintiff can maintain this action in any shape. Rut the decision settles no other point, particularly not the question as to whether the plaintiff had any right of action either legal or equitable, as the judges did not agree on this point, one of them holding that the plaintiff had no right of action whatever, and the other holding he had a right of action in equity for an account and for the payment of the balance found due him on such account.

The result from the above views is, that the judgment must be reversed, and a new trial ordered, for the reason that the plaintiff, to entitle himself to any recovery, must show at least a sufficient excuse or reason for his non-performance.

It is not, however, intended to be decided that if he succeeds in showing a sufficient excuse he will be entitled to a recovery.

Whether showing a sufficient excuse will give him a prima facie cause of action or not, and whether if it does, it may not be overcome by other facts and circumstances, are questions which had better be reserved until they come before us in a case the judgment wherein is founded on such excuse or such other facts and circumstances.

Judgment reversed and a new trial ordered, with costs .of appeal to the appellant, to abide the event.  